TERMS & CONDITIONS (for Clients / Project Work)

PLEASE READ CAREFULLY. THESE TERMS GOVERN YOUR CONTRACT WITH ZUNIGAS CONSTRUCTION 1 CORP.

1. Parties & Scope

This agreement is between you (the “Client” / “Homeowner”) and Zunigas Construction 1 Corp (“Contractor,” “we,” “us”). It governs the services, payments, rights, and obligations for the project described in the signed contract or proposal.

2. Licensing & Registration

3. Written Contract Requirement (for > $500 Projects)

  • Per NJ law, any home improvement contract over $500 (and any changes) must be in writing and signed by both parties New Jersey Division of Consumer Affairs+3New Jersey Division of Consumer Affairs+3ansell.law+3

  • The contract must plainly set forth:
      • Legal name, business address, contractor’s registration or license number, and your (client’s) name and address
      • Description of work, materials, model numbers, quality, scope, location
      • Contract price / consideration, including finance charges or interest
      • Start and completion dates or time frame
      • Warranties, guarantees on materials, workmanship
      • Any security interest or mortgage or financing terms
      • Statement that the contract contains no blank spaces
      • Notice of the three-day right of cancellation in bold 10-point type (or larger) stating:

“YOU MAY CANCEL THIS CONTRACT AT ANY TIME BEFORE MIDNIGHT OF THE THIRD BUSINESS DAY AFTER RECEIVING A COPY OF THIS CONTRACT. IF YOU WISH TO CANCEL, YOU MUST EITHER: (i) SEND A SIGNED AND DATED WRITTEN NOTICE BY REGISTERED OR CERTIFIED MAIL, RETURN RECEIPT REQUESTED; OR (ii) PERSONALLY DELIVER A SIGNED & DATED WRITTEN NOTICE TO: [Contractor Name, Address, Phone]. IF YOU CANCEL, YOU ARE ENTITLED TO A FULL REFUND OF ANY PAYMENT MADE. WE MUST MAKE THE REFUND WITHIN 30 DAYS AFTER RECEIPT OF YOUR NOTICE.”
  • Insurance certificate(s) (e.g. general liability, workers’ compensation) including insurer name and policy limits
  • Subcontractor disclosure (if any work is subcontracted)

  • Failure to comply with contract requirements can subject a contractor to liability under the NJ Consumer Fraud Act (triple damages, attorneys’ fees) ansell.law+1

4. Project Changes & Change Orders

  • Any change in scope, materials, or schedule must be documented in writing as a change order, signed by both parties

  • Change orders may adjust price or timeline accordingly

5. Payment Terms

  • Payments may be made via ACH, Zelle, or other approved method

  • Payment milestones or deposit structure must be set out in contract

  • Final payment is due upon substantial completion, subject to punch-list and inspection

  • Late payments may accrue interest at the rate specified in contract (not to exceed legal limits)

6. Subcontractors & Third Parties

  • We may engage subcontractors or vendors to perform portions of the work

  • You consent that subcontractors may access your property to perform their tasks

  • We remain responsible for oversight and quality control

7. Warranties / Guarantees

  • We warrant workmanship for a period (e.g. 1 year) and specify material warranties if provided

  • These warranties are in lieu of all other warranties, including implied warranties, to the extent permitted by law

  • We disclaim warranties for damage caused by misuse, neglect, or modifications by others

8. Permits, Inspections & Code Compliance

  • Client is responsible (unless otherwise agreed) for obtaining necessary permits and paying fees

  • Work will comply with applicable building codes and regulations

  • Inspections and approvals are required milestones

9. Delays, Force Majeure & Unforeseen Conditions

  • We are not liable for delays due to weather, acts of God, supply chain issues, regulatory or permit delays, or other unforeseen conditions

  • If hidden conditions (e.g. structural problems, unknown utilities) arise, we will propose adjustments in scope and cost

10. Right to Cancel & Refunds

  • You may cancel as described in the three-day cancellation notice above

  • Upon cancellation, any payments made must be refunded within 30 days of notice receipt

  • After three days, cancellation is subject to contract terms

11. Limitation of Liability & Indemnification

  • To the maximum extent permitted by law, our liability is limited to direct damages up to the contract price

  • We disclaim consequential, incidental, punitive damages

  • You agree to indemnify and hold us harmless from claims arising from your breach, misuse, or negligent acts

12. Dispute Resolution & Governing Law

  • This contract is governed by the laws of New Jersey

  • Any dispute shall be resolved by arbitration [or in state court — choose one] in [county], NJ (or specify)

  • Each party bears its own attorneys’ fees, unless the law or contract provides otherwise

13. Severability & Entire Agreement

  • If one provision is invalid under NJ law, the rest remain in force

  • This contract (plus exhibits, change orders, etc.) is the entire agreement, superseding prior negotiations

14. Notices

  • Notices must be in writing (email or certified mail) to addresses in the contract

  • Delivery is effective upon receipt

15. Amendment

  • We may amend the contract or terms only by mutual written agreement..